线上期刊服务咨询,发表咨询:400-808-1701 订阅咨询:400-808-1721

建造合同8篇

时间:2023-03-01 16:23:14

建造合同

建造合同篇1

“业主”指___________________________。

“承包商”指_________________________。

“工厂”指在附录_________中指定的构成固定设备的全部机器、设备和材料。

“工地”指按本合同用于建造工厂的全部土地。

“工程”指承包商按本合同实施的工程。

“合同价格”指业主向承包商支付的全部工程款项。

第二条 承包商的职责

1.承包商应负责设计、筹划以及在工地上建造工厂。

2.除了业主根据第_________条提供的项目和设施,承包商应提供所有为使工厂成功建造所必需的设备、材料、工具、设施、劳工和服务。

3.承包商应根据附录_________中的日程安排施工。

4.承包商应根据附录_________中的规定为业主培训工厂设备的操作和维修人员。

5.承包商应向业主提供附录_________中规定的备件。

6.承包商应向业主提供附录_________中指定的维修设备。

第三条 业主的职责

1.业主应提供工地,并在本合同有效期内允许承包商自由地、不受干扰地出入该工地。

2.业主应按时提供附录_________中指定的物件和设施。

3.业主将从有关部门获取为工厂建造、设备运行所必需的执照和许可证,包括承包商雇员的工作许可证。

4.业主应按第_________条中规定的合同价格向承包商支付工程款项。

第四条 合同价格

1.在本合同生效后_________天内,业主应向承包商支付金额为合同价格,作为承包商完成该工程并承担本合同规定的所有义务的全部报酬。

2.合同价格不再上调,完成工种的成本风险应由承包商承担,商定合同价格时应认为承包商已获得全部信息并已把所有可能影响成本的因素估计在内。

第五条 设计图样

1.承包商应根据合同,在附录_________规定的时间内向业主提交工厂建造所需的图样,供业主审批。业主应在收到这些图样后一个月内,对图样进行审核,并作出批准或不批准的决定。

2.承包商应对上述图样中的任何缺点、错误或疏漏负责,除非这种缺点、错误或疏漏是因业主书面提供的不准确信息所致。

3.业主或承包商互相提供的所有图样和技术资料,收到方应作为机密文件对待,除非另有商定,收到方不得将这些图样和资料用于与本合同无关的其他目的。

第六条 检验

1.承包商应该按法律和正常的工程惯例的要求,负责工厂所有的检验和试验工作。

2.业主有权在任何适当时间对建造中的工厂的材料和工艺进行检验和测试,费用自理。这种检验或测试不能免除承包商在合同中应尽的任何义务。

3.完工后的工厂应由业主进行检验和测试;工厂何时可以测试,承包商应提前以书面形式通知业主。

4.承包商应根据业主的合理要求,为彻底而有效的检测提供所需要的协助、劳力、材料、电力、燃料、设备、备用品和仪器。

5.工厂通过上述测试后,业主应向承包商签发一份表示通过测试的证书。检测中发现的任何问题未圆满解决,工厂不得移交。

第七条 工地

建造合同篇2

乙方: 身份证号:

因甲方公司发展需要,需聘用____(建筑)专业____(一)级建造师,经过真诚友好协商,甲方同意聘用乙方,在乙方的配合下为其办理注册手续,具体条款如下:

一、 聘用期限

甲方聘用乙方的期限为 年。即注册成功(即建设部门网上正式公告之日)起往后推 年。

二、 甲方权利与义务

1、合同期间,甲方有权使用乙方的注册证书申报甲方公司的企业资质及年检。免费为乙方办理初始注册、续期注册、变更注册、年检等相关手续,并在《执业手册》上登记聘用期间的执业情况。

2、合同期间,甲方工程项目由乙方担任项目经理的,须另行签订协议并支付相关责任报酬(证件用于招投标时;需乙方出场时,甲方承担全部的差旅费及交通费,另每天给予乙方补助500元整),甲方工程项目乙方不担任项目经理的,乙方不承担工程项目的相关责任。

3、合同期间,甲方负责乙方每年的继续教育、注册业务培训(含继续教育期间的差旅住宿费用)等相关费用,乙方凭相关票据向甲方报销。在政府政策允许的情况下,若乙方因工作原因,无法参加再教育学习,甲方有义务请人代之学习。

4、甲方应妥善保管乙方的注册证书及其他有关材料。注册建造师执业印章及其它证书原件应在注册成功后(10工作日内)及时交还乙方本人保管,甲方如需使用乙方注册章时,必须将图纸等交由乙方审查,乙方同意后盖章。不得以乙方的名义进行非法活动,否则由因此造成的后果,由甲方负相应的法律责任。

5、甲方应根据协议要求,按时支付乙方的聘用工资。

6、签定协议时,甲方应向乙方提供其单位的营业执照、施工资质证、组织机构代码证的复印件。

7、甲方应及时办理并申报注册(变更)手续,在政府规定的行政许可办事工作日内完成注册。

三、 乙方权利与义务

1、双方签定协议后,乙方应于 年 月 日向甲方提供有关建造师注册所需要的相关材料【建造师执业资格合格证书、学历证书、身份证、职称证书、一寸、二寸彩色相片等】。

2、在甲方办理资质年检及建设行政主管部门的检查时,乙方需配合甲方并及时提供有关身份证、职称证明文件、学历文凭等证明材料。乙方有义务及时(5个工作日)向甲方提供相关证件。

3、甲方在申请注册期间,乙方积极配合甲方进行初始注册,以便顺利注册成功。

4、乙方提供的证件必须合法有效、若乙方原因导致甲方注册不成功时,及时退还甲方支付的预付工资 元人民币。

5、及时提醒甲方支付聘用工资及提供银行帐号。

四、 聘用工资及支付方式

1、经双方商定,甲方同意每年支付乙方 元整聘用工资(税后)。甲方确认乙方证书和签订协议后支付乙方 元 的聘用工资预付款。注册成功公告后5个工作日内,支付给乙方第一年聘用工资余款 人民币。甲方电汇到乙方指定的银行卡中,第二年付款日期与前一年日期一样。

2、如果注册过程中由于甲方的原因导致注册未成功,甲方应支付乙方从协议签订之日起到协议解聘日期间的聘用工资,每月1000元标准。

3、甲方,乙方签订协议之日至注册成功公告,非乙方原因超过约定期限时既开始计算聘用工资。

五、 证书及印章的保管

完成注册后,乙方同意将《注册证书》交由甲方管理,甲方应妥善加以保管。执业印章由乙方自己保管。

六、 解聘

1、在协议有效期内,甲乙双方不得擅自单方解除协议,如因此造成损失,由擅自解除协议一方负责。如果甲乙双方在协议期内需要变动协议,应本着相互支持与理解的原则,提前一个月通知对方,以便另一方做好工作安排。

2、如果双方同意解除协议,甲方应提前30天给出具乙方解聘证明、职业道德证明等有关转注册证明,方便乙方办理转注手续,协议到期即返还乙方留存在甲方处的所有证明文件及证书原件,甲方负责乙方转注册时当地转出的手续办理,不得无故刁难。

3、在下列情况下,乙方有权提前解除协议:

(1) 甲方不能按期支付工资; (2)注册不成功; (3)甲方有其它违约行为。

七、 违约责任

1、甲方负责乙方在注册期内的再教育学习的一切费用及手续,如甲方无法在注册期满前完成乙方的再教育学习手续和转注册的证明材料,造成乙方无法转注册,甲方应向乙方赔偿人民币 5 万元整。

2、由于甲方原因造成乙方的资格证、注册证丢失或吊销;甲方赔偿乙方相关损失,其相关损失计算方法如下:

资格证、注册证丢失,甲方应负责为乙方补办;不耽误乙方正常注册,否则、甲方须继续支付乙方聘用工资到证书发下来为止。

大学文凭(原件)因甲方过失而丢失损毁,甲方应赔付乙方 10万 元整;

资格证吊销,甲方赔付乙方 10万 元整。

3、因乙方自身原因导致后果,甲方概不负责。

4、乙方必须在甲方公司注册满 年,才可以转注,乙方要求提前解聘,则甲方不负责再教育学习费用,乙方退还甲方当年聘用工资,且赔付甲方违约金 5万 元整。

5、甲方必须在注册满 年,才可以解聘,如提前解聘,甲方赔付乙方违约金 5万 元整。

6、甲方在注册(变更)成功公告后不按协议约定支付报酬及交付建造师注册印章,经乙方提醒仍不履约的视为提前解聘。

7、乙方若提供虚假的注册证件及相关文件,不积极配合甲方变更注册时视为提前解聘。

8、甲方、乙方签订协议之日至注册成功公告期限不能超过100天。变更注册不能超过40天。

八、 本协议条款货币形式均为人民币。

九、 续聘

聘用期满,双方有意签订续聘协议,具体条件由双方另行商议,格式可采用本协议。

十、 本协议一式两份。双方各执壹份,具同等效力。

十一、 本协议自双方签定之日起生效,聘用期满解聘,聘用工资付清、相关证明文件返还乙方后失效。

十二、 本协议所指金额均为税后金额,如本协议发生缴税情况,均由甲方承担,本协议为劳动合同的附件之一。

十三、未尽事宜,双方再协商解决。

十四、争议解决办法:原则上双方协商解决,协商不成时由人民法院裁决。

十五、附则

对于甲方需要乙方注册证书参与工程项目投标和项目管理经营活动,应征得乙方同意,须另行签订相关协议。甲方将给予乙方一定的政策性责任工资补助。

甲 方:(签字盖章) 乙方(签字):

法人代表:

经 办 人: 代 表:

电 话: 家庭电话:

建造合同篇3

“业主”指_________。

“承包商”指_________。

“工厂”指在附录_________中指定的构成固定设备的全部机器、设备和材料。

“工地”指按本合同用于建造工厂的全部土地。

“工程”指承包商按本合同实施的工程。

“合同价格”指业主向承包商支付的全部工程款项。

第二条 承包商的职责

1.承包商应负责设计、筹划以及在工地上建造工厂。

2.除了业主根据第_________条提供的项目和设施,承包商应提供所有为使工厂成功建造所必需的设备、材料、工具、设施、劳工和服务。

3.承包商应根据附录_________中的日程安排施工。

4.承包商应根据附录_________中的规定为业主培训工厂设备的操作和维修人员。

5.承包商应向业主提供附录_________中规定的备件。

6.承包商应向业主提供附录_________中指定的维修设备。

第三条 业主的职责

1.业主应提供工地,并在本合同有效期内允许承包商自由地、不受干扰地出入该工地。

2.业主应按时提供附录_________中指定的物件和设施。

3.业主将从有关部门获取为工厂建造、设备运行所必需的执照和许可证,包括承包商雇员的工作许可证。

4.业主应按第_________条中规定的合同价格向承包商支付工程款项。

第四条 合同价格

1.在本合同生效后_________天内,业主应向承包商支付金额为合同价格,作为承包商完成该工程并承担本合同规定的所有义务的全部报酬。

2.合同价格不再上调,完成工种的成本风险应由承包商承担,商定合同价格时应认为承包商已获得全部信息并已把所有可能影响成本的因素估计在内。

第五条 设计图样

1.承包商应根据合同,在附录_________规定的时间内向业主提交工厂建造所需的图样,供业主审批。业主应在收到这些图样后一个月内,对图样进行审核,并作出批准或不批准的决定。

2.承包商应对上述图样中的任何缺点、错误或疏漏负责,除非这种缺点、错误或疏漏是因业主书面提供的不准确信息所致。

3.业主或承包商互相提供的所有图样和技术资料,收到方应作为机密文件对待,除非另有商定,收到方不得将这些图样和资料用于与本合同无关的其他目的。

第六条 检验

1.承包商应该按法律和正常的工程惯例的要求,负责工厂所有的检验和试验工作。

2.业主有权在任何适当时间对建造中的工厂的材料和工艺进行检验和测试,费用自理。这种检验或测试不能免除承包商在合同中应尽的任何义务。

3.完工后的工厂应由业主进行检验和测试;工厂何时可以测试,承包商应提前以书面形式通知业主。

4.承包商应根据业主的合理要求,为彻底而有效的检测提供所需要的协助、劳力、材料、电力、燃料、设备、备用品和仪器。

5.工厂通过上述测试后,业主应向承包商签发一份表示通过测试的证书。检测中发现的任何问题未圆满解决,工厂不得移交。

第七条 工地

1.承包商应在工地上提供所有令业主满意的材料、劳力、设备、服务和便利,以便顺利施工和完工。

2.在总体上得到上述保证的前提下,承包商应提供下列各项必需品:

a.建筑设备;

b.工地上使用的运输工具,包括临时道路;

c.保护人员和财产安全所需的篱笆、灯光、岗哨以及所有其他材料和服务;

d.为材料和施工人员(包括业主雇员)提供临时仓库、办公室和其他房屋建筑;

e.在整个工程移交之前提供电话、灭火设备和急救设备;

f.供施工人员使用的卫生设备和食堂。

3.承包商应遵守当地法律规定的所安全及其他条例。

4.无论何时,承包商都不应在业主的房产及其邻近建筑物、车道和街道上堆积施工用建筑材料和建筑垃圾,工程完工后,应从建筑物及其周围清除所有用剩的材料,保持工地和工厂安全、整洁,以备使用。

第八条 承包商的工作人员

1.承包商将自费为其全部工作人员提供饮食、交通及一切必要的便利。

2.合同签署后,承包商应指定一名项目经理,在工程进行过程中全权代表承包商。他将在工作时间内坐镇施工现场。业主向项目经理发出的所有指示,如同发给承包商本人一样,同样具有约束力。

3.如果业主认为工地上承包商的雇员品行不端、不能胜任工作或有失职行为,可要求承包商将此人调离或更换。

第九条 责任

1.在工厂被最终验收之前,承包商应对工厂的任何损失或损坏负责,并自费将其修复,直至业主满意。然而,如果根据本合同,这类损坏的责任不在承包商,而业主要求予以修复,承包商应按业主指示办理,但费用由业主负担。

2.在最后验收合格证书签发之前,凡因承包商或其分包商的疏忽,或设计、材料或工艺上的缺陷而产生的任何财产损失或人身伤害,承包商应向业主赔偿,并保护业主免受由此而产生的各种诉讼、索赔、要求或费用支出。

3.如果业主因某种原因遭受索赔或诉讼,而按本条款规定承包商应该或可能对该事由承担法律责任,则业主应立即书面通知承包商。承包商应以业主名义接手并通过谈判处理解决或能由此而产生的诉讼,并承担一切费用。如承包商要求,业主应向承包商提供承包商为处理此类索赔或诉讼所需要的所有资料和帮助。

第十条 保险

1.在不限制承包商责任的情况下,承包商将自费投保下列险:

a.机器设备从工厂交货到目的地的运输险。

b.为承包商和分包商的所的雇员投保雇员赔偿险,或者根据适用的法律和法规投保类似的法定社会保险。

c.防备财产损坏或人身伤害的产品责任险,期限到维修期结束,每次事件的金额不少于_________美元。

d.对承包商或其分包商在执行本合同中使用的所有车辆投保综合汽车责任险。

2.上述保险单应以承包商及其分包商、业主、及其工程师、顾问、雇员、人为联合投保人。保险单应包含保险人放弃对业主及其工程师、顾问、雇员及人的代位权之条款。

3.承包商应保持上述保单的完全有效性,直到本合同对其规定的义务解除为止。业主有权随时索取保单、背书、续保和保险费收据的复印件。如果承包商未能全面投保,业主应有权代表承包商办理上述保险,支付所有相关保费,并从支付给承包商的款项中扣除有关费用。

第十一条 完工

1.一俟工厂的全部建设和安装工程完工,承包商应通知业主,并根据附录_________的规定进行机械安装完成测试工作,直至业主满意。

2.测试圆满结束后,业主应签发一份完工证明书。在完工证明书签发之前,不得给工厂进料。

3.如果在建造和安装中出现不影响完成安装的小缺陷,或者在测试中测出不影响工厂开工的缺陷,业主应签发完工证明书,而承包商则有义务尽快修复这些不足之处。

第十二条 最后验收

1.完工证明书颁发之后,承包商应提前_________天将工厂性能测试的时间通知业主。

2.为使测试准时开始,业主应按附录_________中的要求提供原料和其他设备,而承包商应按通知的时间开始性能测试。

3.性能测试将按附示_________的规定进行。测试成功后,业主应签发一份最后验收证明书,证明工厂已从证书签发日起移交业主。

4.如果工厂未能通过性能测试,承包商在进行他认为必要的调整之后,应在业主在场的情况下重新进行测试,时间由双方商定,条件照旧。

5.在最后验收合格证书签发之前,工厂不得投入商业性运转。如工厂未能通过性能测试,业主仍可酌情颁发最后验收合格证书,条件是承包商必须尽快纠正工厂存在的问题。

第十三条 违约赔偿金

1.如果由于承包商的原因导致性能测试的再次失败,而双方并无继续重新测试的协议,则对最后一次测试的结果进行评估。承包商将根据附录_________的规定向业主支付违约赔偿费,费率不超过合同价格的_________%。

2.如果承包商因自身的原因未能在合同生效后的_________个月内获得整个工厂的最后验收合格证书,承包商须根据附录_________的规定向业主每月支付相当于合同价格_________%的拖延赔偿费,但最多不超过合同价格的_________%。

3.承包商应根据附录_________规定的格式开立一份以业主为受益人、金额为合同价格_________%的保证书,作为其履行本条款项下义务的保证。

第十四条 保修

1.承包商保证,在最后验收合格证书签发日起_________个月内或本合同生效日期_________个月内(以先到日期为准),所提供的工厂无设计、材料和工艺上的缺陷。

2.发现问题后,如果承包商的代表在现场工作,业主应在_________天内按本条款以书面形式向承包商提出全部要求;如果承包商的代表不在现场,业主应在_________天内以航空邮件将确证材料发往承包商总公司。承包商应更换或修理所有有缺陷的零部件。为此,应允许承包商随时自由出入工地,检查缺损部件,使其能履行本保修条款。如果承包商因某种特殊情况未能在适当期限内进行双方同意的补救工作,业主有权自行修复,但费用由承包商负担。

3.本保修的先决条件是,业主须按承包商的指示和具体规定的性能参数对工厂进行装备、操作和维护。如果业主未经承包商同意试图自行修正,则本保修条款无效。

4.本保修条款不包括因自然损坏的物件,也不包括使用寿命不到_________个月的消耗品或类似物件。

5.如果承包商遵照上更换任何设备、材料或工艺,则本保修条款的规定也适用于经修理或更换的设备、材料或工艺,期限为从修理或更换完成之日起1年。

第十五条 专利权和专利使用费

1.承包商应全力保护业主在使用其提供的工帮时免遭因侵犯第三方的专利、设计或版权而面临的诉讼、索赔、要求和各种费用。

2.如果承包商提供的工程设计、工厂设备的制造和供应以及在工程建造中实施的工作或使用的方法涉及了第三方的专利,他也应向终第三方支付按许可证或许可知要款规定应支付的所有费用、专利使用费和其他款项。但是,如果业主在经营或使用该厂或其中任何部分时涉及了第三方的专利,他应向第三方支付按许可证或许可条款规定应支付的所有费用、专利使用费和其他款项。

第十六条暂停

1.业主有权随时向承包商发出书面通知,指示其暂停工程的任何部分或整个工程,如果暂停期超过_________天,则按合同第_________条规定作终止合同处理。

2.如果业主未能按照本合同在规定日期_________天内向承包商支付任何款项,或者如果承包商因业主在履行合同上的失误而被中断或拖延了工程的进行,承包商有权暂停执行本合同。

3.如果工程按本条款规定暂停,承包商有权收取附加费用,以补偿由于此类暂停、中断和拖延,以及本合同的合理延期执行所造成的成本增加。

第十七条 合同终止

1.按照第_________第规定,如果暂停时间持续超过_________天,任何一方都有权通知另一方立即终止本合同。

2.业主可以随时书面命令承包商停工,承包商在收到终止命令后应停止工地上所有的工作,但工程师出于保护、安全目的,或整理已建的或正在安装的工程,这类工作仍可继续。承包商在收到终止命令后,也应立即停止所有正在工地外进行的履行合同的工作。

3.根据本条款和第_________条规定,合同终止后,承包商有权收取下列费用:

a.与所完成的工程和劳务相应的那部分合同价格;

b.与已完成但未移交的工厂相应的那部分合同价格。

第十八条 不可抗力

1.如果任何一方因不可抗力而款能履行或推迟履行其义务,则不对另一方负责,也不应视作违反合同。

2.“不可抗力”指业主或承包商无法控制的情况,使当事人未能按本合同履行其义务,或者不得不延迟履行其义务。下列情况均被视作“不可抗力”:

a.战争、敌对事件、外敌行动、入侵、类似战争的军事行动(不管是事宣战)、内战;

b.士兵哗变、民众暴乱、军事叛乱、起义、造反、革命、篡权、或者任何个人代表某个组织或与某个组织有联系、旨在以暴力合法或现存政府、或以恐怖主义或暴力对政府施加影响的行为;

c.地震、洪水、火灾或其他自然灾害;

d.所有港口、机场、船运或其他公共交通工具的使用均遭拒绝;

e.工人罢工、工厂停工、或其他的劳工联合行动,影响了承包商和分包商履行其义务;

f.当事人无法控制、从而使其不能履行义务的其他任何意外情况。

3.如果本合同任何一方因不可抗力不能或延迟履行本合同规定的任何义务,他可将不可抗力和由此造成的延迟或妨碍情况通知另一方。发出通知的一方允许根据具体情况及妨碍或延迟持续的时间免于履行或推迟履行合同。

4.根据本第款第3分条规定,如果任何一方免于履行或推迟履行其义务的时间持续了_________个月,那么任何一方都可随时向另一方发出书面通知,终止本合同。

第十九条 转让及分包

1.承包商有权按其惯例分包本合同或本合同的任何部分,而不解除承包商履行本合同的任何义务。

2.事先未经另一方书面同意,任何一方都不得将本合同或其中的权利、义务,或合同的任何部分转让或让与第三方,除非公司合并或改组。如出现此种情况,任何一方都不应毫无理由地予以拒绝。

第二十条 宣传

承包商在作与本合同相关的宣传材料的散发或公开宣布前,应征得业主的同意。

第二十一条 合同生效日

1.本合同生效日为双方签字后,业主获得当事人双方各自有关当局的所有必要批文之日。

2.如果本合同自签字之日起_________天内仍不能生效,合同即被视作无效,除非双方另有商定。

第二十二条 法律和规定

1.承包商应在与履行本合同有关的所有事务中遵守所有适用的法律、法规和命令。

2.本合同的解释、效力和履行,应完全以_________国的法律为准。

第二十三条 完整合同

1.本合同是与约双方之间的完整协议,它取代了以前所有与本合同事项有关的洽谈、说明及口头或书面协议。

2.对本合同的任何修改或补充,须经业主和承包商双方的书面同意。

第二十四条 合同语言

本合同以中文和英语起草,并以英文本为准,对方双均有约束力。

第二十五条 通知

1.按本合同发出的每个通知、同意、指示、命令或决定,应以书面形式发送。发送方式有:向对方有关官员当面递交,或预付邮资航空传递,或通过电报、电传,或先发电报后信件确认。通讯地址如下:

业主:_________;

承包商:_________。

2.如果通知、同意、请求和其他文件发往某个海外目的地,在邮寄日后第_________天应视作已经送交;如果发往国内目的地,在邮寄日后第_________天视作已经送交。用电报、电传发出的通知、同意或请求应视作当天送达。

3.按本条款发送的所有通知、同意、批示或决定,应由有关方正式授权的代表签字。任何一方任何时候如欲变动收件地址,应以书面形式通知对方。

承包商(盖章):_________

业主(盖章):_________

代表人(签字):_________

代表人(签字):_________

_________年____月____日

_________年____月____日

签订地点:_________

签订地点:_________

附件

article 1- definitions

"the owner" shall mean_________

"the contractor" shall mean_________

"the plant" shall mean all or any part of the machinery, equipment and materials forming the permanent installation as specified in appendix(_________).

"the site" shall mean all the land where the plant is to be constructed in accordance with this contract.

"the works" shall mean the works to be done by the contractor under this contract.

"the contract price" shall mean the total sum payable to the contractor by the owner for the works.

article 2- contractor's responsibilities

1. the contractor shall design, engineer, and construct the plant at the site.

2. the contractor shall provide all equipment, materials, tools, facilities, labour and services necessary for the successful construction of the plant except those items and facilities to be supplied by the owner under article (_________).

3. the contractor shall perform the works in accordance with the schedule in appendix (_________).

4. the contractor shall provide the owner's personnel with training of operation and maintenance of the plant in accordance with appendix (_________).

5. the contractor shall supply the owner with the spare parts specified in appendix (_________).

6. the contractor shall supply the owner with the maintenance equipment specified in appendix (_________).

article 3- owner's responsibilities

1. the owner shall make available the site and grant the contractor free and uninterrupted access thereto throughout the duration of this contract.

2. the owner shall provide those items and facilities specified in appendix (_________) at the time therein established.

3. the owner will obtain from the relevant authorities those licenses and permits necessary to construct and operate the plant on the site including work permit for the contractor's employees.

4. the owner shall pay the contractor for the works performed the contract price set out in article (_________).

article 4- contract price

1. within (_________) days after the effective date of this contract, the owner shall pay the contractor as full and complete compensation for accomplishing the works and assuming all obligations under this contract the contract price in the amount of _________.

2. the contract price is not subject to escalation, and the cost of executing the works shall be the risk of the contractor who shall be deemed to have obtained all information and taken into account all circumstances which may affect the cost in agreeing the contract price.

article 5- drawings

1. the contractor shall submit to the owner for approval and review within the time specified in appendix (_________) such drawings as may be required for construction of the plant under this contract. within one month after receiving such drawings the owner shall review and approve or disapprove the drawing.

2. the contractor shall be responsible for any defects, errors or omissions in the above drawings unless such defects, errors or omissions are caused by inaccurate information furnished in writing to the contractor by the owner.

3. all drawings and technical documentation delivered by the owner or the contractor to the other party shall be treated as confidential by the receiving party unless agreed otherwise, and shall not be used by that party for purposes other than those connected with this contract.

article 6- inspection

1. the contractor shall perform all inspection and testing of the plant required by law and normal engineering practice.

2. the owner shall be entitled at all reasonable times and at its own cost to inspect, examine and test the materials and workmanship of the plant under construction. such inspection, examination or testing if made shall not release the contractor from any obligation under the contract.

3. the completed plant shall be inspected, examined and tested by the owner, and the contractor shall give the owner reasonable notice in writing of the date on which the plant will be ready for testing.

4. the contractor shall provide such assistance, labour, materials, electricity , fuels, apparatus, stores and instruments as may be required and as may be reasonably demanded to carry out such tests by the owner properly and efficiently.

5. when the plant shall have passed the above tests, the owner shall furnish the contractor with a certificate in writing to that effect. no plant shall be delivered until any faults discovered during inspection are satisfactorily rectified.

article 7- inspection

1. the contractor shall provide at the site to the reasonable satisfaction of the owner all materials, labour, equipment, services and facilities that may be necessary for the proper execution and completion of the works. 2. without prejudice to the generality of the above, the contractor shall provide, as may be necessary, the following:

(1)construction equipment.

(2)means of transport within the site including temporary roadways.

(3)fencing, lighting and guarding and all other materials and services necessary for the safety and security of persons and property.

(4)temporary stores, offices and other buildings or structures for materials and persons engaged in the words, including persons employed by the owner.

(5)telephones, fire-fighting equipment and first-aid equipment until the whole works have been taken over.

(6)sanitary and canteen facilities for the use of persons engaged in the works.

3. the contractor shall observe all safety and other regulations imposed on the site by local laws.

4. the contractor shall at all times keep the owner's property and the adjoining premises, driveways and streets free of construction materials and rubbish caused by the works, and at the completion of the works shall remove all remaining materials from and about the premises and shall leave the site and plant safe, clean and ready for use.

article 8- inspection

1. the contractor will supply at his own cost food, transprot and all necessary facilities for all his own personnel.

2. on signing the contract, the contractor shall appoint a project manager who will represent the contractor at all times be present at the site during working hours. all communications issued by the owner to the project manager shall be binding as if given to the contractor.

3. the owner may request the removal and replacement of any person employed by the contractor on the site if such person is in the owner's opinion guilty of misconduct, incompetence or negligence.

article 9- inspection

1. the contractor shall be responsible for all losses of or damage to the plant before final acceptance, and shall make good al such loss or damage at the cost of the contractor and to the reasonable satisfaction of the owner provided, however, in the case of loss or damage to the plant arising from or occasioned by causes for which the contractor is mot responsible under the contract, the same shall be made good by the contractor but at the cost of the owner, if the owner so directs.

2. the contractor shall indemnify the owner in respect of all damage and injury occurring before the issue of the final acceptance certificate to any property and person and against all actions, suits, claims, demands, charges and expenses arising in connection therewith which shall be occasioned by the negligence of the contractor or any of his sub-contractors or by defective design, materials or workmanship but not otherwise.

3. in the event of any claim being made or actions brought against the owner arising out of any matter in respect of which the contractor is or may be liable under this article, the owner shall promptly notify the contractor in writing thereof and the contractor shall at his own expense take over and conduct in the name of the owner all negotiations for the settlement of the same and any litigation that may arise therefrom. the owner shall at the request of the contractor afford all such information and assistance as the contractor may reasonably require for the purpose of dealing with any such claim or action.

article 10- inspection

1. without limiting the contractor's liabilities the contractor will at his own expense take out the following insurance:

(1)transportation insurance on the machine and equipment from its delivery ex works to arrival at the site.

(2)workers compensation insurance for all contractor's and subcontractor's employees engaged or similar statutory social insurance in accordance with the applicable laws and regulations.

(3)product liability insurance against damage to property or injury to persons until the end of the maintenance period in the sum not less that (amount) us dollars per occurrence.

(4)comprehensive automobile liability insurance in respect of all vehicles used by the contractor or his sub-contractor in connection with his contract.

2. the aforesaid policies of insurance will be taken out in the names of the contractor and its sub-contractors, the owner, their engineer, consultant and employees and agents as the joint insured and the policies shall contain a waiver of insurer's rights of subrogation against the owner, its engineer, consultant and employees and agents.

3. the contractor shall maintain the aforesaid policies in full force and effect until the discharge of his obligations under this contract, and the owner shall have the right to demand from time to time copies of the policies, endorsements and renewals and receipts for payment of insurance premiums. if the contractor fails to maintain any of these policies in full force and effect, the owner shall have the right to rake out such policies and pay all relative premiums on behalf of the contractor and to deduct the relevant costs from and sums owing to the contractor.

article 11- inspection

1. on completion of all construction and erection work of the plant, the contractor shall inform the owner and shall carry out mechanical erection completion tests specified in appendix (_________) to the satisfaction of the owner.

2. on satisfactory completion of such tests the owner will issue a certificate of completion of erection of the plant. no feedstock shall be fed into the plant until a certificate of completion of erection has been issued.

3. in the event of minor deficiencies in the construction and erection work which do not prevent erection completion and/or in the event of defects revealed by the tests which do not prevent the start-up of the plant, the owner shall issue a certificate of completion of erection and the contractor shall be obliged to rectify the deficiencies as quickly as possible thereafter.

article 12- inspection

1. following the issue of the certificates of completion of erection the contractor shall give the owner (_________) days notice of the date when he will be ready to carry out performance tests of the plant.

2. the owner shall provide the feedstock and other facilities required in appendix (_________) to enable the tests to commence on time and the contractor shall begin the performance tests at the time so notified.

3. the performance tests will be carried out in acceptance with the provisions of appendix (_________) and on their successful completion, the owner shall issue a final acceptance certificate stating that the plant has been taken over by the owner as from the date thereof.

4. if the plant fails to pass its performance test, then the contractor, after making such adjustments as he considers necessary, shall repeat such tests in the presence of the owner at a time to be agreed upon under the same terms and conditions as the original tests.

5. the plant shall not be commercially operated before the issue of the final acceptance certificate. notwithstanding the failure of the plant to pass its performance tests, the owner may at his discretion issue a final acceptance certificate subject to the contractor remedying the plant defects as soon as possible.

article 13- inspection

1. in the event of any repeat of a performance test failing for reasons imputable to the contractor, and there being no mutual agreement to continue re-testing, the results of the final test will be measured and the contractor will be liable to pay to the owner liquidated damages on the scale set out in appendix(_________) up to a maximum of (_________)% of the contract price.

2. if the contractor is unable for reasons within his control to obtain a final acceptance certificate for the whole plant by(_________) months from the effective date of this contract, he shall be liable to pay to the owner for each month's delay liquidated damages of(_________)% of the contract price up to a maximum of (_________)% of the contract price in accordance with appendix(_________).

3. the contractor shall establish, in favour of the owner, a guarantee for(_________)% of the contract price in the form set out in appendix(_________) in support of his obligations under this article.

article 14- inspection

1. the contractor warrants, for a period of (_________) months from the date of issue of the final acceptance certificate or(_________) months from the effective date of this contract whichever is the earlier, the supplied plant against faulty design, material and workmanship.

2. the owner shall inform the contractor in writing of all claims arising under this provision within(_________)days of the detection of fault, if the contractor's representative is on site or within(_________)days if not, to the contractor's head office by telex r recorded air mail delivery with supporting data. the contractor shall have the option to replace or repair all parts proved deficient. for this purpose the contractor shall have the option to replace or repair all parts proved deficient. for this purpose the contractor shall have an access to the site to inspect the faulty parts at any time and to enable him to comply with the terms of this guarantee. should the contractor fail to carry out agreed remedial work within any period of time reasonable in the particular circumstance, the owner shall have the right to do this work at the contractor's expense.

3. this warranty is given subject to the owner storing, operating and maintaining the plant in accordance with the contractor's instructions and specified operating parameters and may be nullified in the event of the owner attempting rectification work without the contractor's agreement.

4. this warranty does not include items which fail due to natural wear and tear, or consumables or similar items whose natural life is (_________) months or less.

5. if pursuant to the above warranty the contractor repairs or replaces any equipment, materials or workmanship, the provisions of this article shall them apply to said repaired or replaced equipment, materials or workmanship for a period of one year from the date such repairs or replacements are completed.

article 15- patent rights and royalties

1. the contractor shall fully indemnify the owner against all actions, claims, demands, costs, charges and expenses arising from or incurred by reason of any infringement of patents, design or copyright of third parties by the use of the plant supplied by the contractor.

2. the contractor shall also be responsible for the payment to third parties of all fees, royalties and other charges, if and, that may be payable under the terms of any license or permission in respect of any design of the works provided by the contractor, the manufactured and supply of the plant and any work done or method employed in the construction of the works. however, the owner shall be responsible for the payment to third parties of all fees, royalties and other charges, if any, that may be payable under the terms of any license or permission in respect of the operation or use of the plant or any part thereof.

article 16- suspension

1. the owner shall have the right to instruct the contractor to suspend any part or the whole of the works at any time upon giving written notice to the contractor provided that any period of suspension exceeding (_________) days shall be treated as termination under article (_________)。

2. if the owner fails to make any payment to the contractor under this contract within (_________) days of the due date, or if the contractor is otherwise interrupted or delayed in the performance of the works due to the owner's contractual default, the contractor shall be entitled to suspend performance of this contract.

3. in the event of suspension of the works in accordance with this article the contractor shall be entitled to receive such reasonable additional payment as may be necessary to compensate for the additional costs arising out of such suspension, interruption or delay and such reasonable extension of time for performance of contract.

article 17- termination

1. in the event of suspension in accordance with article (_________) lasting for a period of more than (_________) days either party shall have the right to give notice to the other party of the immediate termination of this contract.

2. the owner may at any time by written order to the contractor order the contractor to cease further execution of the works, and the contractor shall upon receipt of a termination order, cease all further work on the site other than such work thereon as the engineer may instruct for the purpose of protecting, making safe or tidying up such parts of the works as may already have been executed or be in course of erection. the contractor shall, as soon as practicable after receipt of the termination order, also cease all such further work as is being done off the site in the performance of this contract.

3. upon termination of this contract under this article and under article (_________), the contractor shall be entitled to be paid:

(1)that part of the contract price which is proportionate to engineering and services carried out, and

(2)that part of the contract price which is proportionate to the plant completed but not delivered.

article 18- force majeure

1. no party to this contract shall be liable to the other party for any failure of or delay in performance of its obligations hereof nor be deemed to be in breach of this contract, if such failure or delay has arisen from "force majeure."

2. "force majeure" means circumstances and conditions beyond the control of either parties, that would render it impossible for either the owner or the contractor to fulfill their obligations under this contract, or delay such fulfillment. any of the following matters are considered "force majeure."

(1)war, hostilities, act of foreign enemy, invasion, warlike opera-tions (whether war to be declared or not) or civil war;

(2)mutiny, civil commotion assuming the proportions of or amounting to a popular rising, military rising, insurrection, rebellion, revolution, military or usurped power, or any act of any person acting on behalf of or in connection with any organization with activities directed towards the overthrow by force of the government de jure or de facto, or to the influencing of it by terrorism or violence;

(3)earthquake, flood, fire or other natural physical disaster;

(4)denial of the use of all ports, airports, shipping services or other means of public transport;

(5)trike or lock out or other industrial concerted action by workers, affecting the fulfillment of contractor's and subcontractors' obligations;

(6)and other unforeseen circumstances beyond the control of the parties so affected rendering the fulfillment of their obligations impossible.

3. if either party to this contract is prevented or delayed from or in performing any of his obligations under this contract by force majeure, then he may notify the other party of the circumstances constituting the force majeure and of the obligation performance of which is thereby delayed or prevented and the party giving the notice shall thereupon be excused from the performance or punctual performance, as the case may be, of such obligation for so long as the circumstances of prevention or delay may continue.

4. if by virtue of the preceding sub-clause dither party shall be excused from the performance or punctual performance of any obligation for a continuous period of (_________) months, then either party may at any time thereafter terminate this contract by giving a written notice to the other party.

article 19- assignment and sub-contractors

1. the contractor shall have the right to sub-contract this contract or any part thereof in accordance with his usual practice without relieving the contractor of the obligations of performing this contract.

2. neither party shall without the previous consent in writing of the other party assign or any part thereof to any third party, except in the case of a company amalgamation or reconstruction, provided that such consent shall not be unreasonably withheld.

article 20- publicity

the contractor shall obtain the owner's approval prior to making any publicity releases or public announcements relating to this contract.

article 21- effective date of the contract

1. the effective date of this contract shall be the date after its execution when all the necessary approvals of the respective authorities have been obtained by the owner.

2. if the contract does not become effective within(_________) days from the date of execution, it will be deemed void unless otherwise agreed between the parties.

article 22- law and regulations

1. the contractor shall in all matters relating to the performance of this contract conform with all applicable laws, regulations and orders of central or local authorities.

2. the construction, validity and performance of this contract shall be governed in all respects in accordance with the laws of _________

article 23- entire contract

1. this contract constitutes the entire agreement between the parties hereto and supersedes all prior negotiations, representations or agreements whether oral or in writing relative to the subject matter of this contract.

2. this contract shall be altered or supplemented only by mutual consent in writing between the owner and the contractor.

article 24- language of the contract

this contract was drafted in english language and the english text of this contract shall be valid and binding upon the parties hereto.

article 25- notices

1. every notice, consent, instruction, order or decision given under this contract shall be given or made in writing and either personally served on an officer of the party to whom it is given or airmailed post-prepaid or sent by telegram, telex or cable subsequently confirmed by letter, addressed as follows: to:the owner (address) _________to: the contractor (address) _________.

2. notices, consents, requests and other documents shall be deemed delivered or given, if mailed to an overseas destination, on the (_________) th day after the date of mailing and, if mailed to a domestic destination, the (_________) th day after the date of mailing. notices, consents or requests sent by telegram, telex or cable shall be deemed delivered or given on the day they are despatched.

3. any notice, consent, instruction, or decision given under this article shall be signed on behalf of either party by any duly authorised representative of that party. either of the parties may change his address for receipt of notices, instructions or decisions and other documents at any time by giving notice thereof in writing to the other party.

the owner (signature):_________

the contractor(signature):_________

建造合同篇4

引言

1.本准则规范建造承包商建造工程合同的会计核算和相关信息的披露。

2.由于建造合同的开工日期与完工日期通常分属于不同的会计年度,因此,本准则的主要问题是将合同收入和合同成本分配计入实施工程的各个会计年度。

在一个会计年度内完成的建造合同,应在完成时确认合同收入和合同费用。

定义

3.本准则使用的下列术语,其定义为:

(1)建造合同,指为建造一项资产或者在设计、技术、功能、最终用途等方面密切相关的数项资产而订立的合同。

(2)固定造价合同,指按照固定的合同价或固定单价确定工程价款的建造合同。

(3)成本加成合同,指以合同允许或其他方式议定的成本为基础,加上该成本的一定比例或定额费用确定工程价款的建造合同。

(4)完工百分比法,指根据合同完工进度确认收入与费用的方法。

合同分立与合同合并

4.一般情况下,本准则适用于单项建造合同。

5.如果一项建造合同包括多项资产,在同时具备下列条件的情况下,每项资产应分立为单项合同处理:

(1)每项资产均有独立的建造计划;

(2)建造承包商与客户就每项资产单独进行谈判,双方能够接受或拒绝与每项资产有关的合同条款;

(3)每项资产的收入和成本可单独辨认。

6.一组合同无论对应单个客户还是几个客户,在同时具备下列条件的情况下,应合并为单项合同处理:

(1)该组合同按一揽子交易签订;

(2)该组合同密切相关,每项合同实际上已构成一项综合利润率工程的组成部分;

(3)该组合同同时或依次履行。

合同收入

7.合同收入包括:

(1)合同中规定的初始收入;

(2)因合同变更、索赔、奖励等形成的收入。

8.合同收入应以收到或应收的工程价款计量。

9.合同变更指客户为改变合同规定的作业内容而提出的调整。因合同变更而增加的收入,应在同时具备下列条件时予以确认:

(1)客户能够认可因变更而增加的收入;

(2)收入能够可靠地计量。

10.索赔款指因客户或第三方的原因造成的、由建造承包商向客户或第三方收取的、用以补偿不包括在合同造价中的成本的款项。因索赔款而形成的收入,应在同时具备下列条件时予以确认:

(1)根据谈判情况,预计对方能够同意这项索赔;

(2)对方同意接受的金额能够可靠地计量。

11.奖励款指工程达到或超过规定的标准时,客户同意支付给建造承包商的额外款项。因奖励而形成的收入,应在同时具备下列条件时予以确认:

(1)根据目前合同完成情况,足以判断工程进度和工程质量能够达到或超过既定的标准;

(2)奖励金额能够可靠地计量。

合同成本

12.合同成本应包括从合同签订开始至合同完成止所发生的、与执行合同有关的直接费用和间接费用。

13.合同的直接费用包括:

(1)耗用的人工费用;

(2)耗用的材料费用;

(3)耗用的机械使用费;

(4)其他直接费用,包括有关的设计和技术援助费用、施工现场材料的二次搬运费、生产工具和用具使用费、检验试验费、工程定位复测费、工程点交费用、场地清理费用等。

14.间接费用是企业下属的施工单位或生产单位为组织和管理施工生产活动所发生的费用,包括临时设施核销费用和施工、生产单位管理人员工资、奖金、职工福利费、劳动保护费、固定资产折旧费及修理费、物料消费、低值易耗品摊销、取暖费、水电费、办公费、差旅费、财产保险费、工程保修费、排污费等。

15.直接费用在发生时应直接计入合同成本,间接费用应在期末按照系统、合理的方法分摊计入合同成本。

16.与合同有关的零星收益,例如合同完成后处置残余物资取得的收益,应冲减合同成本。

17.合同成本不包括下列费用:

(1)企业行政管理部门为组织和管理生产经营活动所发生的管理费用;

(2)船舶等制造企业的销售费用;

(3)企业筹集生产经营所需资金而发生的财务费用。

18.因订立合同而发生的有关费用,应直接确认为当期费用。

合同收入与合同费用的确认

19.如果建造合同的结果能够可靠地估计,企业应根据完工百分比法在资产负债表日确认合同收入和费用。

20.固定造价合同的结果能够可靠估计是指同时具备下列条件:

(1)合同总收入能够可靠地计量;

(2)与合同相关的经济利益能够流入企业;

(3)在资产负债表日合同完工进度和为完成合同尚需发生的成本能够可靠地确定;

(4)为完成合同已经发生的合同成本能够清楚地区分和可靠地计量,以便实际合同成本能够与以前的预计成本相比较。

21.成本加成合同的结果能够可靠估计是指同时具备下列条件:

(1)与合同相关的经济利益能够流入企业;

(2)实际发生的合同成本,能够清楚地区分并且能够可靠地计量。

22.企业确定合同完工进度可以选用下列方法:

(1)累计实际发生的合同成本占合同预计总成本的比例;

(2)已经完成的合同工作量占合同预计总工作量的比例;

(3)已完合同工作的测量。

23.采用累计实际发生的合同成本占合同预计总成本的比例确定合同完工进度时,累计实际发生的合同成本不包括下列内容:

(1)与合同未来活动相关的合同成本,例如施工中尚未安装、使用或耗用的材料成本;

(2)在分包工程的工作量完成之前预付给分包单位的款项。

24.当期完成的建造合同,应按实际合同总收入扣除以前会计年度累计已确认的收入后的余额确认为当期收入,同时按累计实际发生的合同成本扣除以前会计年度累计已确认的费用后的余额确认为当期费用。

25.如果建造合同的结果不能可靠地估计,应区别以下情况处理:

(1)合同成本能够收回的,合同收入根据能够收回的实际合同成本加以确认,合同成本在其发生的当期确认为费用。

(2)合同成本不可能收回的,应在发生时立即确认为费用,不确认收入。

26.如果合同预计总成本将超过合同预计总收入,应将预计损失立即确认为当期费用。

披露

27.企业应披露下列与建造合同有关的事项:

(1)在建合同工程累计已发生的成本和累计已确认的毛利(或亏损);

(2)在建合同工程已办理结算的价款金额;

(3)当期确认的合同收入和合同费用的金额;

(4)确定合同完工进度的方法;

(5)合同总金额;

(6)当期已预计损失的原因和金额;

(7)应收帐款中尚未收到的工程进度款。

附则

建造合同篇5

甲方:

乙方: (二级建造师) 身份证:

甲方因工程业务拓展的需要特向社会招聘建造师。乙方的条件符合甲方的要求。双方经友好协商,乙方愿意应聘在甲方单位任职建造师相应的岗位工作。为认真履行各方的职责,签订合同如下:各方遵守。

一、合同期限

合同期限: 贰 年。 贰年聘用期到期后,双方无异议如需续聘,甲方应事先征得乙方同意。如乙方不同意,合同无效,甲方须归还乙方所有证件(印章)以及及时配合乙方办理变更所需要的资料、手续,不得拖延。

二、甲方责任与义务

1、聘用期内及时做好建造师继续教育的各项审验和培训工作,并承担聘用期间的审验和培训费。

2、薪资待遇

二级建造师薪资待遇: 元/年(大写: ),合同期限为叁年( 年 月 日至 年 月 日),共 元(大写: )(税后)。乙方建造师与企业在浙江省厅办理建造师变更注册手续办完后,甲方在一天内一次性支付给乙方 贰 年共30000.00 元整(RMB 三万元整)。

招投标、会议等如需乙方到场参加,需提前一周通知乙方,差旅费如有发生按实报销,出差补贴 元/次。如工程中标,甲方支付乙方项目奖 元 (大写: )(税后)。

建造师的证书和职业资格章保管在甲方处,甲方在有关要求需履行建造师资格印章等权利时必须事先告知乙方本人同意,否则造成有关纠纷及后果由甲方承担。

三、乙方责任与义务

1、准时参加配合甲方的招投标等活动;

2、积极参加工程中标后,甲方工程建设中需要乙方出席的相关活动和会议。

3、建造师的证书和职业资格章保管在甲方处;

4、乙方保留一切因甲方履行建造师职权的知情权,甲方应及时将履行情况告知乙方。

5、通讯、住址等的信息变更及时通知甲方。

四、合同的解除

1、在合同有效期内,甲乙双方不得擅自单方解除合同,如因此造成损失,由擅自解除合同一方负责。如果甲乙双方在合同期内需要变动合同,应本着相互支持与理解的原则,提前二个月通知对方,以便另一方做好工作安排。

2、在下列情况下,双方有权提前解除合同:

(1)乙方不能提供甲方所需的证书资料及不能及时配合甲方需要的,甲方可提前解除本合同并可向乙方索赔,索赔内容包括已支付的未履约时间段的聘用费及由于乙方不配合造成的甲方损失;

(2)甲方不能按期及时支付乙方相关的薪资待遇,乙方可单方提前解除本合同。

3、非双方原因未最终注册成功,双方互换证件后本合同解除。

五、违约责任

1、乙方若在合同期内在除甲方以外的单位再行注册建设部注册类执业资格的,影响甲方经营或给甲方造成损失的,甲方有权追究乙方法律及违约责任,并赔偿甲方的相关损失。

2、在合同期内甲方如未能按合同约定及时支付乙方相关薪资待遇,乙方有权单方提前终止本合同,甲方须向乙方赔偿违约金伍仟元整。甲方须在十五个工作日内协助乙方申请办理变更注册。

3、乙方无故要求提前解除合同的,应符合浙江省关于二级建造师变更注册的相关规定,并提前两个月通知甲方,并赔偿甲方违约金伍仟元整。

六、其他约定

1、乙方在职期间,承担项目负责人的工程在投标、中标后的施工中到保修期终止前所致的工程质量、安全等责任均由甲方负责。

2、合同期内如果乙方因参加配合甲方的招投标及会议等活动造成的意外事故,甲方须按照相关的法律法规承担乙方的损失。

3、本合同有不尽之处双方友好协商解决。

4、本合同一式二份,甲乙双方各执一份。

甲方:(盖章) 乙方:(签字)

法定代表人:(签字)

联系地址: 联系地址:

联系电话: 联系电话:

建造合同篇6

一、计入合同成本的各项费用:

直接费用,由于直接费用在发生时能够分清受益对象,所以直接费用在发生时直接计入合同成本;间接费用,间接费用虽构成了合同成本的组成内容,但间接费用在发生时一般不宜直接归属于受益对象,而应在资产负债表日按照系统、合理的方法分摊计入合同成本;二、与建造合同相关的借款费用:

建造承包商为客户建造资产,通常是客户筹集资金,并根据合同约定,定期向建造承包商支付工程进度款。建造承包商在合同建造期间发生的借款费用,符合《企业会计准则第17号借款费用》规定的资本化条件,应当计入合同成本。

三、因订立合同而发生的费用:

建造合同篇7

乙方: 身份证号码:

因发展需要,甲方需聘用国家注册二级建造师(房建专业),经过真诚协商,双方达成如下聘用条款:

一、注册聘用期:甲方聘用乙方的注册期限为 壹 年,每年薪金为: 元整,薪资支付方式为:壹年一付。

二、乙方应向甲方提供二级建造师执业资格合格证、毕业证书、身份证(原件)乙方一寸二寸彩色相片各4张,以及其它甲方注册过程中需要的一些证明材料。

在当日验证完成双方签定本合同后,甲方即付给乙方 元整,并报销原返程车旅费。乙方的身份证和毕业证甲方在报送上级主管部门审核后归还(十五个工作日左右)第二年若甲方继续聘用乙方,第二年薪金由甲方在合同到期前提前一个月一次性支付给乙方。

乙方姓名: 开户行: 银行帐号: .

三、甲方办理注册期限为50个工作日,超过 50 个工作日视同注册成功,必须付给上述款项;若因乙方原因,导致不能完成注册时,乙方应将已收到的薪资全部退还给甲方,并收回全部证件(甲方均应出具有效书证予以证实)若是甲方单位原因导致乙方不能完成注册的,则退还首付款的50%.

四、聘用期间,若国家开通对建造师继续教育,乙方在聘用期内的继续教育(含继续教育期间标准的差旅住宿费用)均由甲方负担,乙方凭相关票据向甲方报销。如因甲方需要乙方到公司配合的,甲方应提前与乙方协商,报销原返程车旅费、食宿费。

五、完成注册后,乙方只作为甲方资质升级和年检之用,乙方的“注册证书、执业资格证书”交由甲方妥善保管,其注册章及其他证书原件应交还给乙方。在甲方办理资质申报、年检或有关部门检查时,若需有关证书原件、印章等,乙方应及时配合提供,不得延误。

若超出以上范围,甲方要使用乙方证书或印章时,则应经双方协商,经乙方书面同意后,方可使用,并付给相应报酬或津贴。如甲方不经乙方同意私自使用所引起的一切后果由甲方承担。

六、在合同期内,甲方应为乙方在《执业手册》上登记聘用期间的执业情况,并为乙方办理该证的年检工作,年检费用由甲方支付,乙方若有其他需要注册的证件,甲方有义务协助乙方办理相关注册手续;甲方保证乙方资格证件的年检及时、有效,保证乙方继续教育等工作的及时进行。

七、解聘:乙方必须在聘用合同的壹年期满后,才可转注,在合同期满时,甲方应提前30天出具乙方的解聘证明、职业道德证明等有关转注册证明,方便乙方办理转注的手续。乙方要求提前解聘的,也应提前30天通知甲方说明具体情况,并应退还已收的辞聘后期间的薪资,且甲方不再负担其再教育学习费用。甲方要求提前解聘的,则应支付剩余期间的薪资。

八、续聘:聘用期满,双方有意签订续聘合同,具体事宜由双方另行协商。

九、违约责任:

甲方负责乙方在注册期内的再教育学习的一切费用及手续,如甲方没有在注册期满前完成乙方的再教育学习手续和转注册的证明材料,造成乙方无法转注的,甲方应向乙方赔偿因此延期的薪金,且由甲方办理转注手续,直至乙方能转注为止。

如果由于甲方原因发生乙方的证件丢失,甲方应赔偿乙方相关损失,金额如下:若资格证、注册证丢失,甲方负责补办,如造成经济损失由甲方进行赔偿;由于大学文凭(原件)无法补办,若丢失损毁,甲方应赔付乙方伍万元整;如因乙方自身原因造成不良后果,甲方概不负责。

十、本合同所指薪资均为税后金额,如需缴税,均由甲方承担。

十一、双方如有争议或纠纷时,可协商或提请仲裁部门仲裁。

十二、本合同一式两份。双方各执壹份,具同等效力。

甲方:

乙方:

代表人:

电话:

年 月 日

建造合同篇8

乙方: 身份证号码:

因发展需要,甲方需聘用国家注册二级建造师(房建专业),经过真诚协商,双方达成如下聘用条款:

一、注册聘用期:甲方聘用乙方的注册期限为 壹 年,每年薪金为: 元整,薪资支付方式为:壹年一付。

二、乙方应向甲方提供二级建造师执业资格合格证、毕业证书、身份证(原件)、乙方一寸二寸彩色相片各4张,以及其它甲方注册过程中需要的一些证明材料。

在当日验证完成双方签定本合同后,甲方即付给乙方 元整,并报销原返程车旅费。乙方的身份证和毕业证甲方在报送上级主管部门审核后归还(十五个工作日左右)。第二年若甲方继续聘用乙方,第二年薪金由甲方在合同到期前提前一个月一次性支付给乙方。

乙方姓名: 开户行: 银行帐号: 。

三、甲方办理注册期限为50个工作日,超过 50 个工作日视同注册成功,必须付给上述款项;若因乙方原因,导致不能完成注册时,乙方应将已收到的薪资全部退还给甲方,并收回全部证件(甲方均应出具有效书证予以证实)。若是甲方单位原因导致乙方不能完成注册的,则退还首付款的50%。

四、聘用期间,若国家开通对建造师继续教育,乙方在聘用期内的继续教育(含继续教育期间标准的差旅住宿费用)均由甲方负担,乙方凭相关票据向甲方报销。如因甲方需要乙方到公司配合的,甲方应提前与乙方协商,报销原返程车旅费、食宿费。

五、完成注册后,乙方只作为甲方资质升级和年检之用,乙方的“注册证书、执业资格证书”交由甲方妥善保管,其注册章及其他证书原件应交还给乙方。在甲方办理资质申报、年检或有关部门检查时,若需有关证书原件、印章等,乙方应及时配合提供,不得延误。

若超出以上范围,甲方要使用乙方证书或印章时,则应经双方协商,经乙方书面同意后,方可使用,并付给相应报酬或津贴。如甲方不经乙方同意私自使用所引起的一切后果由甲方承担。

六、在合同期内,甲方应为乙方在《执业手册》上登记聘用期间的执业情况,并为乙方办理该证的年检工作,年检费用由甲方支付,乙方若有其他需要注册的证件,甲方有义务协助乙方办理相关注册手续;甲方保证乙方资格证件的年检及时、有效,保证乙方继续教育等工作的及时进行。

七、解聘:乙方必须在聘用合同的壹年期满后,才可转注,在合同期满时,甲方应提前30天出具乙方的解聘证明、职业道德证明等有关转注册证明,方便乙方办理转注的手续。乙方要求提前解聘的,也应提前30天通知甲方说明具体情况,并应退还已收的辞聘后期间的薪资,且甲方不再负担其再教育学习费用。甲方要求提前解聘的,则应支付剩余期间的薪资。

八、续聘:聘用期满,双方有意签订续聘合同,具体事宜由双方另行协商。

九、违约责任:

推荐范文
推荐期刊